Terms and Conditions

This Website is Owned and Operated by QUEEKLY, a QueekStarter LLC

PLEASE READ THE FOLLOWING TERMS AND CONDITIONS CAREFULLY BEFORE USING THIS SITE. By using this site, you signify your agreement to these Terms and Conditions. If you do not agree to these Terms and Conditions, do not use this site. QUEEKLY may modify these Terms and Conditions at any time. All questions should be directed to hello@queekly.co

General

You confirm that you are at least 18 years of age or are accessing the Site under the supervision of a parent or legal guardian. You agree that if you are unsure of the meaning of any part of the Terms and Conditions of Sale, you will not hesitate to contact us for clarification prior to making a purchase. These Terms and Conditions of Sale fully govern the sale of goods and services purchased on this Site.

Personal Information

Your submission of personal information through the store is governed by our Privacy Policy which can be viewed on our site.

Errors, Inaccuracies and Omissions

Occasionally there may be information on our site or in the Service that contains typographical errors, inaccuracies or omissions that may relate to product descriptions, pricing, promotions, offers, product shipping charges, transit times and availability. We reserve the right to correct any errors, inaccuracies or omissions, and to change or update information or cancel orders if any information in the Service or on any related website is inaccurate at any time without prior notice (including after you have submitted your order).

In the event that an item is mispriced, we may, at our own discretion, either contact you for instructions or cancel your order and notify you of such cancellation.

We shall have the right to refuse or cancel any such orders whether or not the order has been confirmed and your credit/debit card charged. In the event that we are unable to provide the services, we will inform you of this as soon as possible. A full refund will be given where you have already paid for the products.

Modifications To Prices

Prices for our products are subject to change without notice. We reserve the right at any time to modify or discontinue the Service (or any part or content thereof) without notice at any time.
We shall not be liable to you or to any third-party for any modification, price change, suspension or discontinuance of the Service.

Delivery

We provide digital products that can be delivered over the internet. Therefore, this Site is for the delivery of products/services to customers anywhere in the world. We make every effort to deliver products/services within the estimated timescales set out on our site; however, delays are occasionally inevitable due to unforeseen factors. We shall be under no liability for any delay or failure to deliver the products within the estimated timescales where they did not occur due to our fault or negligence.

You agree not to hold us liable for any delay or failure to deliver products/services or otherwise perform any obligation as specified in these Terms and Conditions of Sale if the same is wholly or partly caused whether directly or indirectly by customers or circumstances beyond our reasonable control.

Products and Services

Our products or services are available exclusively online through the website. These products or services are subject to return or exchange only according to our Return Policy.

We reserve the right but are not obligated, to limit the sales of our products or services to any person, geographic region or jurisdiction. We may exercise this right on a case-by-case basis. We reserve the right to limit the quantities of any products or services that we offer. All descriptions of products or product pricing are subject to change at any time without notice, at our sole discretion. We reserve the right to discontinue any product at any time. Any offer for any product or service made on this site is void where prohibited.

We do not warrant that the quality of any products, services, information, or other material purchased or obtained by you will meet your expectations, or that any errors in the Service will be corrected.

Refunds

Our product/Services offering is our brand promise to you and we keep to this, whatever it cost us. We offer only the very best as defined in our offering and legal policies. However, if you require a refund, the following applies:

  • We can guarantee a refund if you send in the request within one hour of submitting the information for your website development.
  • We do not provide a refund if you request it after your domain name or hosting has been purchased.
  • We do not provide a refund if our team has started building your website or if it has been completed.
  • We have a work process that involves payment processing and other teams across the company. The phase where you are in the process at the time of refund request will determine if you get a refund or not. As a result of this, we cannot guarantee a refund.
  • In the case of a refund, you will be charged 5% of the product cost. This is the commission charged by our payment processor and for bank transfers.
    Honouring a refund request is entirely at our discretion. This is to avoid abuse of this process.

Accuracy of Billing and Account Information

You agree to provide current, complete and accurate purchase and account information for all purchases made at our store. You agree to promptly update your account and other information, including your email address and credit card numbers and expiration dates so that we can complete your transactions and contact you as needed.

Indemnification

You agree to indemnify us, our parent, subsidiaries, affiliates, partners, officers, directors, agents, contractors, licensors, service providers, subcontractors, suppliers, interns and employees, harmless from any claim or demand, including reasonable legal fees, made by any third party due to or arising out of your breach of these Terms and conditions of service.

Applicable Law and Jurisdiction

These Terms and Conditions of Sale shall be interpreted and governed by the laws in force in the Federal Republic of Nigeria. Subject to the Arbitration section below, each party hereby agrees to submit to the jurisdiction of the courts of Nigeria and to waive any objections based upon venue.

Arbitration

Any controversy, claim or dispute arising out of or relating to these Terms and Conditions of Sale will be referred to and finally settled by private and confidential binding arbitration before a single arbitrator held in Nigeria in English and governed by Nigeria law pursuant to the Arbitration and Conciliation Act Cap A18 Laws of the Federation of Nigeria 2004, as amended, replaced or re-enacted from time to time.

The arbitrator shall be a person who is legally trained and who has experience in the information technology field in Nigeria and is independent of either party. Notwithstanding the foregoing, the site reserves the right to pursue the protection of intellectual property rights and confidential information through injunctive or other equitable relief through the courts.

Severability

If any portion of these Terms or Conditions of Sale is held by any court or tribunal to be invalid or unenforceable, either in whole or in part, then that part shall be severed from these Terms and Conditions of Sale and shall not affect the validity or enforceability of any other section listed in this document.

Miscellaneous Provisions

You agree that all agreements, notices, disclosures and other communications that we provide to you electronically satisfy any legal requirement that such communications be in writing.

Assigning or sub-contracting any of your rights or obligations under these Terms and Conditions of Sale to any third party is prohibited unless agreed upon in writing by us.

We reserve the right to transfer, assign or subcontract the benefit of the whole or part of any rights or obligations under these Terms and Conditions of Sale to any third party